BETA

5 Amendments of Arba KOKALARI related to 2023/0323(COD)

Amendment 206 #
Proposal for a regulation
Article 4
Article 4 Payments to subcontractors in public procurement 1. For public works contracts falling within the scope of Directives 2014/23/EU, 2014/24/EU, 2014/25/EU, and 2009/81/EC56 of the European Parliament and of the Council, contractors shall provide evidence to contracting authorities or contracting entities within the meaning of those Directives that, where applicable, they have paid their direct subcontractors involved in the execution of the contract within the deadlines and under the conditions set out in this Regulation. The evidence may take the form of a written declaration by the contractor and shall be provided by the contractor to the contracting authority or contracting entity prior to, or at the latest together with, any request for payment. 2. Where the contracting authority or contracting entity has not received the evidence as provided for in paragraph 1 or has information of a late payment by the main contractor to its direct subcontractors, the contracting authority or contracting entity shall notify the enforcement authority of its Member State thereof without delay. __________________ 56 Directive 2009/81/EC of the European Parliament and of the Council of 13 July 2009 on the coordination of procedures for the award of certain works contracts, supply contracts and service contracts by contracting authorities or entities in the fields of defence and security, and amending Directives 2004/17/EC and 2004/18/EC.deleted
2023/12/18
Committee: IMCO
Amendment 206 #
Proposal for a regulation
Article 4
Article 4 Payments to subcontractors in public procurement 1. For public works contracts falling within the scope of Directives 2014/23/EU, 2014/24/EU, 2014/25/EU, and 2009/81/EC56 of the European Parliament and of the Council, contractors shall provide evidence to contracting authorities or contracting entities within the meaning of those Directives that, where applicable, they have paid their direct subcontractors involved in the execution of the contract within the deadlines and under the conditions set out in this Regulation. The evidence may take the form of a written declaration by the contractor and shall be provided by the contractor to the contracting authority or contracting entity prior to, or at the latest together with, any request for payment. 2. Where the contracting authority or contracting entity has not received the evidence as provided for in paragraph 1 or has information of a late payment by the main contractor to its direct subcontractors, the contracting authority or contracting entity shall notify the enforcement authority of its Member State thereof without delay. __________________ 56 Directive 2009/81/EC of the European Parliament and of the Council of 13 July 2009 on the coordination of procedures for the award of certain works contracts, supply contracts and service contracts by contracting authorities or entities in the fields of defence and security, and amending Directives 2004/17/EC and 2004/18/EC.deleted
2023/12/18
Committee: IMCO
Amendment 302 #
Proposal for a regulation
Article 13
Article 13 Enforcement authorities 1. Each Member State shall designate one or more authorities responsible for the enforcement of this Regulation (‘enforcement authority’). 2. Where appropriate, enforcement authorities shall take measures necessary to ensure that the deadlines for payments are complied with. 3. Enforcement authorities shall cooperate effectively with each other and with the Commission and shall provide each other with mutual assistance in investigations that have a cross-border dimension. 4. Enforcement authorities shall coordinate their activities with other authorities responsible for enforcing other Union or national legislation including through exchange of information obligations. 5. Enforcement authorities shall forward the complaints received regarding late payments in the agricultural and food sector to the competent enforcement authorities under Directive (EU) 2019/633.deleted
2023/12/15
Committee: IMCO
Amendment 340 #
Proposal for a regulation
Article 14
Article 14 Powers of enforcement authorities 1. Enforcement authorities shall have the necessary resources and expertise to perform their duties, and shall have the following powers: (a) the power to initiate and conduct investigations on their own initiative or based on a complaint; (b) the power to require creditors and debtors to provide all necessary information to conduct investigations related to late payments in commercial transactions; (c) the power to carry out unannounced on-site inspections within the framework of their investigations; (d) the power to take decisions finding an infringement of this Regulation and requiring the debtor to pay interest for late payment as provided for in Article 5 or requiring the debtor to compensate the creditor as provided for in Article 8; (e) the power to impose, or initiate proceedings for the imposition of fines and other penalties and interim measures on the subjects responsible for the infringement; (f) the power to require the debtor to bring the infringement to an end; (g) the power to publish its decisions referred to in paragraphs (d), (e) and (f). 2. Member States shall lay down the rules on penalties applicable to infringements of this Regulation and shall take all measures necessary to ensure that they are implemented. The penalties provided for shall be effective, proportionate and dissuasive. 3. Member States shall, [by …/without delay], notify the Commission of those rules and of those measures and shall notify it, without delay, of any subsequent amendment affecting them.deleted
2023/12/15
Committee: IMCO
Amendment 358 #
Proposal for a regulation
Article 15
Article 15 Complaints and confidentiality 1. Creditors may address complaints either to the enforcement authority of the Member State in which they are established or to the enforcement authority of the Member States in which the debtor is established. The enforcement authority to which the complaint is addressed shall be competent to enforce this Regulation. 2. Organisations officially recognised as representing creditors or organisations with a legitimate interest in representing undertakings shall have the right to submit a complaint to the enforcement authorities referred to in Article 13 at the request of one or more of their members or, where appropriate, at the request of one or more members of their member organisations, where those members consider that they have been affected by an infringement of this Regulation. 3. Where the complainant so requests, the enforcement authority shall take the necessary measures for the appropriate protection of the identity of the complainant. The complainant shall identify any information for which it requests confidentiality. 4. The enforcement authority that receives the complaint shall inform the complainant within a reasonable period of time after the receipt of the complaint of how it intends to follow up on the complaint. 5. Where an enforcement authority considers that there are insufficient grounds for acting on a complaint, it shall inform the complainant of the reasons of its decision within a reasonable period of time after the receipt of the complaint. 6. Where an enforcement authority considers that there are sufficient grounds for acting on a complaint, it shall initiate, conduct and conclude an investigation of the complaint within a reasonable period of time. 7. Where an enforcement authority finds that a debtor has infringed this Regulation, it shall require the debtor to bring the illegal practice to an end.deleted
2023/12/15
Committee: IMCO